6-5-702
Section 6-5-702 Compliance with contract documents. During the course of construction, a contractor who constructs, maintains, or repairs a highway, road, street, or bridge for the awarding authority is not liable to a claimant for personal injury, property damage, or death arising from the performance of such construction, maintenance, or repair, if, at the time of the personal injury, property damage, or death, the contractor was in compliance with contract documents material to the condition, including the traffic control plan, that was the proximate cause of the personal injury, property damage, or death unless following the plans and specifications would result in a dangerous condition that should have appeared to be defective to a reasonably prudent contractor or that the contractor should have known that following the plans and specifications could create a dangerous condition that caused the injury or death. (Act 2012-225, p. 414, §3.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-702.htm - 1K - Match Info - Similar pages
16-44B-1
Commission may deem appropriate. The executive director shall serve as secretary to the Interstate Commission, but shall not be a Member of the Interstate Commission. The executive director shall hire and supervise such other persons as may be authorized by the Interstate Commission. D. The Interstate Commission's executive director and its employees shall be immune from suit and liability, either personally or in their official capacity, for a claim for damage to or loss of property or personal injury or other civil liability caused or arising out of or relating to an actual or alleged act, error, or omission that occurred, or that such person had a reasonable basis for believing occurred, within the scope of Interstate Commission employment, duties, or responsibilities; provided, that such person shall not be protected from suit or liability for damage, loss, injury, or liability caused by the intentional or willful and wanton misconduct of such person. 1. The liability of...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/16-44B-1.htm - 46K - Match Info - Similar pages
7-9A-102
term includes: (A) proceeds to which a security interest attaches; (B) accounts, chattel paper, payment intangibles, and promissory notes that have been sold; and (C) goods that are the subject of a consignment. (13) "Commercial tort claim" means a claim arising in tort with respect to which: (A) the claimant is an organization; or (B) the claimant is an individual and the claim: (i) arose in the course of the claimant's business or profession; and (ii) does not include damages arising out of personal injury to or the death of an individual. (14) "Commodity account" means an account maintained by a commodity intermediary in which a commodity contract is carried for a commodity customer. (15) "Commodity contract" means a commodity futures contract, an option on a commodity futures contract, a commodity option, or another contract if the contract or option is: (A) traded on or subject to the rules of a board of trade that has been designated as a contract market for such a contract...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/7-9A-102.htm - 29K - Match Info - Similar pages
11-32-7
and trust indentures, or either. (17) Exercise the power of eminent domain, except as limited by state law, except the authority may not acquire, without the consent of the owner, any transportation system from which public transportation service is currently being furnished. The authority may not by eminent domain acquire any real property or rights owned or held by public or private railroads or utilities. (18) Expend funds for the purchase or lease of materials, equipment, supplies, or other personal property without compliance with Chapter 16 of Title 41. (19) Appoint, employ, contract with, and provide for the compensation of, officers, employees, and agents, including, but without limitation to, engineers, attorneys, management consultants, fiscal advisers, or other consultants without regard to Chapter 16 of Title 41, or any law establishing a civil service or merit system that might otherwise be applicable, as the business of the authority may deem necessary or desirable, and...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/11-32-7.htm - 14K - Match Info - Similar pages
6-5-706
Section 6-5-706 Improper maintenance following conclusion of project. A contractor shall bear no civil liability to a claimant for personal injury, property damage, or death which occurs subsequent to the conclusion of the project where the proximate cause of the personal injury, property damage, or death is occasioned by a failure of the awarding authority to properly maintain the roadway or any of its features, including shoulders, unless either: (1) A contractor contracts in whole or in part with the awarding authority to maintain the roadway, or any of its features, including shoulders, or project in question. (2) The contractor undertakes, independent of a contract, to maintain a roadway or any of its features, including shoulders. (Act 2012-225, p. 414, §7.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-706.htm - 1K - Match Info - Similar pages
6-5-701
Section 6-5-701 Reliance upon specifications. A contractor is justified ordinarily in relying upon the specifications that are contained in the contract with an awarding authority. No contractor shall be held civilly liable for work performed on a highway, road, bridge, or street including repairs, construction, or maintenance on behalf of the awarding authority unless it is shown by a preponderance of the evidence that physical injury, property damage, or death is proximately caused by any of the following: (1) A failure by the contractor to follow the plans and specifications resulting in a dangerous condition. (2) The contractor's performance of the contract in compliance with the plans and specifications creates a condition that should have appeared, to a reasonably prudent contractor, to be a dangerous condition. (3) A latent defect which creates a dangerous condition that is the result of the work of the contractor. (Act 2012-225, p. 414, §2.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-701.htm - 1K - Match Info - Similar pages
6-5-711
Section 6-5-711 Exemption from civil liability for certain professional firms and employees providing construction monitoring services. The provisions of Section 34-11-9(a)(3) notwithstanding, neither a professional firm nor any of its employees that provide construction monitoring services on behalf of an awarding authority relating to the construction, repair, resurfacing, refurbishment, replacement, removal, modification, alteration, or other improvement of any public or private infrastructure shall be civilly liable in tort or otherwise for property damage, personal injury, or death resulting from construction monitoring services that substantially comply with the professional firm's construction monitoring services requirements for the awarding authority related to the plans and specifications in determining compliance of the contractor's work with the plans and specifications. (Act 2013-401, p. 1538, §2.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-711.htm - 1K - Match Info - Similar pages
6-5-218
to real property. (a) No action in tort, contract, or otherwise shall be commenced against any person performing or furnishing the design, planning, supervision, or observation of construction or the construction of an improvement to real property more than seven years after the substantial completion of such improvement for the recovery of damages for: (1) Any deficiency in the design, planning, supervision, or observation of construction or construction of such an improvement; or (2) Injury to real or personal property caused by any such deficiency; or (3) Injury to or wrongful death of a person caused by any such deficiency. (b) The prohibition provided in this section shall apply to any action commenced against a person for his own act, or failure to act, or for the act, or failure to act, of his employees; likewise, the prohibition contained in this section shall extend to every demand, whether commenced by direct action or for contribution or indemnity or by third-party...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-218.htm - 2K - Match Info - Similar pages
6-5-712
Section 6-5-712 Construction and application of article. (a) This article is not applicable to the extent that a professional firm or its employees are engaged by an awarding authority solely to design and/or prepare the engineering plans and specifications for a public or private infrastructure. (b) This article is not applicable to the extent that a professional firm or its employees performing construction monitoring services are also engaged by an awarding authority to prepare the engineering plans for that project, or are otherwise providing additional services on that project, and to the extent that a deficiency in such plans or additional services proximately causes property damage, personal injury, or death to a third party with whom the professional firm is not in privity of contract. (c) This article does not replace or supersede existing burdens of proof or defenses in professional liability actions concerning construction monitoring services. (Act 2013-401, p. 1538, §3.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-712.htm - 1K - Match Info - Similar pages
6-5-221
under the supervision, administration, or observation of an architect or engineer, or designed by and constructed in accordance with the plans and specifications prepared by an architect or engineer, for the recovery of damages for: (i) Any defect or deficiency in the design, planning, specifications, testing, supervision, administration, or observation of the construction of any such improvement, or any defect or deficiency in the construction of any such improvement; or (ii) Damage to real or personal property caused by any such defect or deficiency; or (iii) Injury to or wrongful death of a person caused by any such defect or deficiency; shall be commenced within two years next after a cause of action accrues or arises, and not thereafter. Notwithstanding the foregoing, no relief can be granted on any cause of action which accrues or would have accrued more than seven years after the substantial completion of construction of the improvement on or to the real property, and any right...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-221.htm - 3K - Match Info - Similar pages
|