9-9-42
Section 9-9-42 Construction of improvements under water management plan - Authority and procedure for letting contracts. The board of water management commissioners may secure and use men, equipment and materials under the supervision of the water management engineer to construct, excavate and complete all or any of the works of improvements which may be needed to carry out the plan of water management, or it may, in its discretion, let contracts therefor, either as a whole or in part. The board of commissioners shall fix the time and place of letting contracts for the construction of the improvements and cause notice thereof, containing a description of the work to be let, to be made by publication in three consecutive issues of some weekly newspaper (if such there be) of general circulation published in the county in which the district is organized and by at least one insertion in some contractor's or trade journal and by such additional publication elsewhere as the board of water...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-42.htm - 3K - Match Info - Similar pages
9-9-23
Section 9-9-23 Appointment of district engineer, etc.; preparation, adoption, etc., of report and water management plan for improvements in district. (a) Within 60 days after the district is established, it shall be the duty of the board of water management commissioners to appoint as district engineer a competent civil or agricultural engineer of good standing in his profession who is familiar with the type of project involved if said engineer is needed or required by the district. Such services of an engineer may not be required if engineering services are furnished by a federal, state or local agency. (b) In case an engineer is needed or required, it shall be the duty of the court of probate to refer the report of the preliminary survey or other plans to the district engineer, who shall make a survey of the district and shall prepare a report with plans for improvements for the district. Such report shall include maps, profiles, specifications, estimates of cost and other data and...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-23.htm - 4K - Match Info - Similar pages
9-9-53
Section 9-9-53 Joint works of improvement with adjoining states. Whenever it may be desirable to construct, widen, deepen, straighten or otherwise change any ditch, drain, watercourse, floodwater retarding structure, levee or other works of improvement lying on or along, across or near the boundary line between the State of Alabama and an adjoining state or whenever it may be desirable to construct, repair or improve any works of improvement as provided for in this article, which ditch, drain, watercourse, floodwater retarding structure or other works of improvement cannot be constructed, repaired or improved in the best manner without affecting lands in such adjoining state, the board of water management commissioners of the district in which such work is located shall have authority to join with the proper officers of such adjacent county or counties or districts of other states in the construction, widening, deepening, straightening, repairing or improving of any such drain, ditch,...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-53.htm - 2K - Match Info - Similar pages
39-2-2
Section 39-2-2 Advertisement for and opening of sealed bids for public works contracts; violations; exclusions; emergency actions; sole source specification. (a) Before entering into any contract for a public works involving an amount in excess of fifty thousand dollars ($50,000), the awarding authority shall advertise for sealed bids, except as provided in subsection (j). If the awarding authority is the state or a county, or an instrumentality thereof, it shall advertise for sealed bids at least once each week for three consecutive weeks in a newspaper of general circulation in the county or counties in which the improvement or some part thereof, is to be made. If the awarding authority is a municipality, or an instrumentality thereof, it shall advertise for sealed bids at least once in a newspaper of general circulation published in the municipality where the awarding authority is located. If no newspaper is published in the municipality, the awarding authority shall advertise by...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/39-2-2.htm - 9K - Match Info - Similar pages
9-9-15
Section 9-9-15 Board of water management commissioners - Powers and duties generally. The board of water management commissioners shall have the right and authority to enter into contracts or other agreements with the United States government or any department thereof, with persons, with railroads or other corporations, with public corporations, with the state government of this or other states and with drainage, conservation or other improvement districts in this or other states for cooperating or assisting in constructing, maintaining, using or operating the works of the district or for making surveys and investigations or reports thereon and may purchase, lease or acquire land or other property in adjoining states in order to secure outlets or for other purposes of this article, and may let contracts for securing such outlets or other works in adjoining states as may be necessary to carry out the provisions of this article. The board shall have the authority to borrow funds from...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-15.htm - 1K - Match Info - Similar pages
9-9-43
Section 9-9-43 Construction of improvements under water management plan - Duties of water management engineer; payment of contractor. The water management engineer shall have charge of the construction of the plan of water management. He shall make monthly estimates of the amount of work done and shall furnish one copy to the contractor and file the other with the secretary of the board of commissioners, and the commissioners shall within five days after the filing of such estimates meet and direct the secretary to draw a warrant in favor of such contractor for not more than 90 percent of the work done according to the specifications and contract; and, upon the presentation of such warrant, properly signed by the president and secretary, to the treasurer of the district, he shall pay the amount due thereon. When the work is fully completed and accepted by the water management engineer, he shall make an estimate for the whole amount due, including the amounts withheld on previous...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-43.htm - 1K - Match Info - Similar pages
9-9-47
Section 9-9-47 Construction of improvements crossing railroad right-of-way. After a district has let a contract for work which crosses or traverses a railway right-of-way and the actual construction is commenced, the engineer in charge of construction shall notify the railroad company of the probable time at which the contractor will be ready to enter upon the right-of-way of said road and construct the work thereon. It shall be the duty of the said railroad to send a representative to view the ground with the engineer and arrange the exact time at which such work can be most conveniently done. At the time agreed upon, the said railroad company shall remove its rails, ties, stringers and such other obstructions as may be necessary to permit the excavation or construction of the channel or other work of improvement across its right-of-way. The work shall be so planned and conducted as to interfere in the least possible manner with the business of the said railroad. In case the railroad...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-47.htm - 2K - Match Info - Similar pages
9-9-50
Section 9-9-50 Annexation of land to district. Any body of land, however large, contiguous or adjacent to a water management district organized under this article may be annexed thereto and made a part thereof, the same as if originally included therein, upon petition of one third or more of the landowners owning 50 percent or more in acreage of the real property to be annexed or upon the petition of one half or more of the owners of the real property to be annexed owning more than one third of the area to be annexed. Such petition and all the proceedings relative thereto shall conform as nearly as may be with the provisions of this article for the filing of the petition for the organization of a water management district and shall be filed with the court of probate having jurisdiction over the district to which annexation is sought. Upon filing of such petition, the court shall direct the board of water management commissioners of said district to cause surveys and a report to be made...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-50.htm - 3K - Match Info - Similar pages
11-89C-4
Section 11-89C-4 Powers of public corporation; requirements for development or adoption of rules, procedures, ordinances, etc. (a) When expressly required to comply with storm water laws, any public corporation created pursuant to this chapter shall have the following powers: (1) To establish, maintain, and operate an organizational structure pursuant to this chapter, its original or amended certification, and its bylaws or other rules of procedure, that will enable it to implement the storm water laws for and on behalf of any governing body that exercises the option to participate in or with a public corporation, provided that no new or greater authorities or powers other than those specifically granted to the governing bodies are conferred upon any public corporation formed pursuant to this chapter. Except for the authority provided in subdivision (20), authority to enforce the storm water laws is retained wholly and exclusively to the governing bodies and may not be further...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/11-89C-4.htm - 10K - Match Info - Similar pages
37-11A-1
Section 37-11A-1 Execution and text of compact. The Governor, on behalf of this state, shall execute a compact, in substantially the following form, with the State of Mississippi, and the Legislature approves and ratifies the compact in the form substantially as follows: Northeast Mississippi - Northwest Alabama Railroad Authority Compact. The contracting states solemnly agree: Article I. The purpose of this compact is to promote and develop trade, commerce, industry, and employment opportunities for the public good and welfare in northeast Mississippi and northwest Alabama through the establishment of a joint interstate authority to acquire certain railroad properties and facilities which the operator thereof has notified the Interstate Commerce Commission of an intention to abandon and which are located in any of Franklin, Marion, or Winston Counties, Alabama or in Alcorn or Tishomingo Counties, Mississippi. Article II. This compact shall become effective immediately as to the State...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/37-11A-1.htm - 33K - Match Info - Similar pages
|