6-5-218
Section 6-5-218 Rule of prescription regarding damages arising out of improvements to real property. (a) No action in tort, contract, or otherwise shall be commenced against any person performing or furnishing the design, planning, supervision, or observation of construction or the construction of an improvement to real property more than seven years after the substantial completion of such improvement for the recovery of damages for: (1) Any deficiency in the design, planning, supervision, or observation of construction or construction of such an improvement; or (2) Injury to real or personal property caused by any such deficiency; or (3) Injury to or wrongful death of a person caused by any such deficiency. (b) The prohibition provided in this section shall apply to any action commenced against a person for his own act, or failure to act, or for the act, or failure to act, of his employees; likewise, the prohibition contained in this section shall extend to every demand, whether...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-218.htm - 2K - Match Info - Similar pages
6-5-221
Section 6-5-221 Limitation on time for commencement of action. (a) All civil actions in tort, contract, or otherwise against any architect or engineer performing or furnishing the design, planning, specifications, testing, supervision, administration, or observation of any construction of any improvement on or to real property, or against builders who constructed, or performed or managed the construction of, an improvement on or to real property designed by and constructed under the supervision, administration, or observation of an architect or engineer, or designed by and constructed in accordance with the plans and specifications prepared by an architect or engineer, for the recovery of damages for: (i) Any defect or deficiency in the design, planning, specifications, testing, supervision, administration, or observation of the construction of any such improvement, or any defect or deficiency in the construction of any such improvement; or (ii) Damage to real or personal property...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-221.htm - 3K - Match Info - Similar pages
40-27-1
Section 40-27-1 Compact adopted; terms. The following Multistate Tax Compact is hereby approved, adopted and enacted into law by the State of Alabama: Multistate Tax Compact Article I. Purposes. The purposes of this compact are to: 1. Facilitate proper determination of state and local tax liability of multistate taxpayers, including the equitable apportionment of tax bases and settlement of apportionment disputes. 2. Promote uniformity or compatibility in significant components of tax systems. 3. Facilitate taxpayer convenience and compliance in the filing of tax returns and in other phases of tax administration. 4. Avoid duplicative taxation. Article II. Definitions. As used in this compact: 1. "State" means a state of the United States, the District of Columbia, the Commonwealth of Puerto Rico, or any territory or possession of the United States. 2. "Subdivision" means any governmental unit or special district of a state. 3. "Taxpayer" means any corporation, partnership, firm,...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/40-27-1.htm - 42K - Match Info - Similar pages
6-5-225
Section 6-5-225 Time for commencement of action against architects, engineers, and builders. (a) It is the purpose and intent of the Legislature in connection with all actions against architects and engineers, who perform or furnish the design, planning, specifications, testing, supervision, administration, or observation of the construction of an improvement on or to real property, and builders who construct, perform, or manage the construction of an improvement on or to real property designed by and constructed under the supervision, administration or observation of, or in accordance with the plans and specifications prepared by, an architect or engineer, to limit the time for commencement of an action to a period of two years from the date a cause of action accrues and to bar all causes of action and rights of action which accrue more than seven years after substantial completion of such improvement. The Legislature finds that this classification distinguishing architects,...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-225.htm - 7K - Match Info - Similar pages
40-29-22
Section 40-29-22 Lien for taxes - Validity and priority against certain persons. (a) Purchasers, holders of security interests, mechanic's lienors, and judgment lien creditors. The lien imposed by Section 40-29-20 shall not be valid as against any purchaser, holder of a security interest, mechanic's lienor, or judgment lien creditor until notice thereof which meets the requirements of subsection (f) has been filed by the Commissioner of Revenue or his delegate, and shall not be perfected as against any purchaser, holder of a security interest, mechanic's lienor, or judgment lien creditor until the date such notice is filed. (b) Protection for certain interest even though notice filed. Even though notice of a lien imposed by Section 40-29-20 has been filed, such lien shall not be valid: (1) SECURITIES. With respect to a security (as defined in subsection (g)(4)): a. As against a purchaser of such security who at the time of purchase did not have actual notice or knowledge of the...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/40-29-22.htm - 17K - Match Info - Similar pages
6-5-227
Section 6-5-227 Causes of action for breach of written express warranty, contract, or indemnity against architects, engineers, and builders. Nothing contained in this article shall be construed to bar, prior to the expiration of a written express warranty, contract, or indemnity, causes of action or rights of action in contract against architects, engineers, and builders as defined in this article arising out of breach of contract for written express warranties, contracts, or indemnities which by the written terms thereof shall extend beyond the period of seven years after the substantial completion of construction of an improvement on or to the real property. Any written express warranty, contract, or indemnity for the purposes of an action in contract based upon the written express warranty, contract, or indemnity shall be enforceable for the period of time specified in writing, and all civil actions in contract arising out of the written express warranty, contract, or indemnity...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-227.htm - 1K - Match Info - Similar pages
6-5-220
Section 6-5-220 Definitions. As used in this article, the following words and phrases used herein shall have the following meaning ascribed to them: (a) BUILDER. Any individual, partnership, firm, or corporation that constructed, or performed or managed the construction of, an improvement, or any portion thereof, on or to real estate, and at the time of the construction was licensed as a general contractor in the State of Alabama. (b) ARCHITECT. Any individual who, at the time the architectural services were performed, was legally qualified to practice architecture and held an unexpired registration as an architect in the State of Alabama; any partnership, corporation, professional corporation, or professional association which, at the time the architectural services were performed, was legally qualified to practice architecture in the State of Alabama; and all employees or agents of the registered architect or of his or her entity or firm acting under the instruction, control, or...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/6-5-220.htm - 4K - Match Info - Similar pages
4-3-47
Section 4-3-47 Powers of authority generally. The authority shall have the following powers, together with all powers incidental thereto or necessary to the discharge thereof in corporate form: (1) To have succession by its corporate name for the duration of time (which may be in perpetuity) specified in its certificate of incorporation; (2) To sue and be sued in its own name in civil actions, excepting actions in tort against the authority; (3) To adopt and make use of a corporate seal and to alter the same at pleasure; (4) To adopt and alter bylaws for the regulation and conduct of its affairs and business; (5) To acquire, receive, take and hold, whether by purchase, option to purchase, gift, lease, devise or otherwise, property of every description, whether real, personal or mixed, whether in one or more counties and whether within or without the corporate limits of any authorizing subdivision, and to manage said property and to develop any property and to sell, exchange, lease or...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/4-3-47.htm - 16K - Match Info - Similar pages
37-6-3
Section 37-6-3 Enumerated powers. A cooperative shall have the power: (1) To sue and be sued in its corporate name. (2) To adopt a corporate seal and alter the same at its pleasure. (3) To generate, manufacture, purchase, acquire and transmit electric energy and to distribute, sell, supply and dispose of electric energy to its members, to governmental agencies and political subdivisions and to other persons; provided, however, that should a cooperative acquire any electric facilities dedicated or devoted to the public use, it may continue to serve the persons served directly from such facilities at the time of such acquisition without requiring that such persons become members, and, provided further, that such nonmembers shall have the right to become members upon nondiscriminatory terms. Cooperatives may not condition membership or provision of service on compliance by the member with requirements not directly related to the electric or other service to be provided by the cooperative....
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/37-6-3.htm - 19K - Match Info - Similar pages
37-11A-1
Section 37-11A-1 Execution and text of compact. The Governor, on behalf of this state, shall execute a compact, in substantially the following form, with the State of Mississippi, and the Legislature approves and ratifies the compact in the form substantially as follows: Northeast Mississippi - Northwest Alabama Railroad Authority Compact. The contracting states solemnly agree: Article I. The purpose of this compact is to promote and develop trade, commerce, industry, and employment opportunities for the public good and welfare in northeast Mississippi and northwest Alabama through the establishment of a joint interstate authority to acquire certain railroad properties and facilities which the operator thereof has notified the Interstate Commerce Commission of an intention to abandon and which are located in any of Franklin, Marion, or Winston Counties, Alabama or in Alcorn or Tishomingo Counties, Mississippi. Article II. This compact shall become effective immediately as to the State...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/37-11A-1.htm - 33K - Match Info - Similar pages
|