9-9-42
Section 9-9-42 Construction of improvements under water management plan - Authority and procedure for letting contracts. The board of water management commissioners may secure and use men, equipment and materials under the supervision of the water management engineer to construct, excavate and complete all or any of the works of improvements which may be needed to carry out the plan of water management, or it may, in its discretion, let contracts therefor, either as a whole or in part. The board of commissioners shall fix the time and place of letting contracts for the construction of the improvements and cause notice thereof, containing a description of the work to be let, to be made by publication in three consecutive issues of some weekly newspaper (if such there be) of general circulation published in the county in which the district is organized and by at least one insertion in some contractor's or trade journal and by such additional publication elsewhere as the board of water...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-42.htm - 3K - Match Info - Similar pages
9-9-25
Section 9-9-25 Correction of errors in or amendments to water management plan. The board of water management commissioners may correct errors in or amend the plan of water management at any time upon the recommendation or concurrence of competent technicians when it appears that the purpose for which the district is organized may thereby be more effectively and economically accomplished; provided, that after assessments of benefits have been confirmed by the court, no such amendment to plans shall be effective until approved by the court having jurisdiction of the district after a hearing, for which notice shall be given as in the case of the assessments of benefits, at which hearing all parties whose property has been assessed for benefits or may be damaged or taken by reason of such amendment shall have opportunity to be heard. When any amendment to the plan is approved by the court, the benefits and damages resulting from such amendment shall be determined at the same hearing. (Acts...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-25.htm - 1K - Match Info - Similar pages
9-9-33
Section 9-9-33 Collection of taxes on property divided, sold or transferred. When any property in a water management district has been divided, sold or transferred, the tax collector may receive taxes levied under this article on a part of any tract, piece or parcel of land or other property and give his receipt accordingly only when the deed or transfer of said property shows the agreed division of said taxes and the approval of the board of water management commissioners of the district. (Acts 1965, No. 685, p. 1246, §26.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-33.htm - 836 bytes - Match Info - Similar pages
9-9-41
Section 9-9-41 Bonds of district employees, etc. Bonds in behalf of the district for the safekeeping of funds and faithful performance of their respective duties and obligations shall be given by each of the commissioners, the engineer, if any, the attorney, the secretary, the treasurer and all other persons who may handle funds of the district and by such persons, firms or corporations having contracts with the district as the commissioners may require. The amount of the bonds and the sureties of the commissioners shall be subject to the approval of the court of probate. The amount of bonds and the sureties of the treasurer, the attorney, the secretary, the engineer, if any, and the contractors shall be subject to the approval of the board of water management commissioners. All bonds of district officials shall be placed with the court of probate and the bonds of contractors with the secretary of the district. The amount of the bonds of any person who handles district funds or of a...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-41.htm - 1K - Match Info - Similar pages
9-10A-6
Section 9-10A-6 Petition to form authority. When 25 or more residents, who are 18 years of age or older, within each county located on a defined watershed desire to form a watershed management authority, said residents shall file a petition with the board of supervisors of the soil and water conservation district in which said proposed authority lies. Such petition shall define the boundaries of the proposed watershed management authority, the number of acres of land involved, reasons for requesting creation of such authority, the proposed name for such watershed management authority and other information pertinent to such proposal. The proposed name of a proposed watershed management authority shall not be the same as, or deceptively similar to, the name of any other watershed management authority. The proposed name shall include references to the geographic features of the area encompassing the watershed management authority. (Acts 1991, No. 91-602, p. 1119, §6.)...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-10A-6.htm - 1K - Match Info - Similar pages
9-9-28
Section 9-9-28 Notice of hearing on report of board of viewers. When the report of the board of viewers is fully completed in accordance with the provisions of this article and filed, the court of probate shall forthwith set a date for hearing said report, not less than 30 days thereafter, and shall give notice thereof by causing publication to be made as hereinafter defined, and the following form shall suffice: "Notice of Filing of Viewers' Report and Hearing Thereon for ___ Water Management District. Notice is hereby given to all persons interested in the following described land and property in _____ County (or Counties), Alabama; (here describe land and property) included within and without _____ water management district, that the board of viewers heretofore appointed to assess benefits and damages to the property and lands situated within and without said water management districts and to appraise the cash value of the land necessary to be taken for rights-of-way for the...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-28.htm - 1K - Match Info - Similar pages
9-9-53
Section 9-9-53 Joint works of improvement with adjoining states. Whenever it may be desirable to construct, widen, deepen, straighten or otherwise change any ditch, drain, watercourse, floodwater retarding structure, levee or other works of improvement lying on or along, across or near the boundary line between the State of Alabama and an adjoining state or whenever it may be desirable to construct, repair or improve any works of improvement as provided for in this article, which ditch, drain, watercourse, floodwater retarding structure or other works of improvement cannot be constructed, repaired or improved in the best manner without affecting lands in such adjoining state, the board of water management commissioners of the district in which such work is located shall have authority to join with the proper officers of such adjacent county or counties or districts of other states in the construction, widening, deepening, straightening, repairing or improving of any such drain, ditch,...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-53.htm - 2K - Match Info - Similar pages
9-9-49
Section 9-9-49 Rights of landowners as to use of drains, watercourses, etc., as outlets for lateral drains from lands. The owner of any land that has been assessed for the cost of the construction of any ditch, drain, watercourse or other improvement as provided in this article shall have the right to use the ditch, drain or watercourse as an outlet for lateral drains from said land; and, if said land is separated from the ditch, drain, watercourse or other drainage improvement by the land of another or others and the owner thereof shall be unable to agree with said other or others as to the terms and conditions on which he may enter their lands and construct said drain or ditch, he may petition to condemn the same and the same proceeding shall be had as in cases of condemnation under the right of eminent domain. When the drain is constructed it shall become a part of the drainage system and shall be under the control of the board of water management commissioners and be kept in repair...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-49.htm - 1K - Match Info - Similar pages
9-9-27
Section 9-9-27 Viewing and assessment of lands by board of viewers; report of findings. (a) Within 30 days after qualifying, the board of viewers shall begin its duties, and it may at any time call upon the attorney of the district for legal advice and information relative to its duties. Said viewers shall proceed to view the premises and determine the value of all land and other property within or without the district to be acquired and used for rights-of-way or other works of drainage, leveeing, reclamation, flood prevention or for the conservation, development, utilization and disposal of water as set out in the water management plan. They shall assess the amount of benefits and the amount of damages, if any, that will accrue to each tract of 40 acres or less, according to the legal or recognized subdivisions of land according to ownership, to public highways, railroad and other rights-of-way, railroads, roadways and other property from carrying out and putting into effect the plan...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-27.htm - 3K - Match Info - Similar pages
9-9-47
Section 9-9-47 Construction of improvements crossing railroad right-of-way. After a district has let a contract for work which crosses or traverses a railway right-of-way and the actual construction is commenced, the engineer in charge of construction shall notify the railroad company of the probable time at which the contractor will be ready to enter upon the right-of-way of said road and construct the work thereon. It shall be the duty of the said railroad to send a representative to view the ground with the engineer and arrange the exact time at which such work can be most conveniently done. At the time agreed upon, the said railroad company shall remove its rails, ties, stringers and such other obstructions as may be necessary to permit the excavation or construction of the channel or other work of improvement across its right-of-way. The work shall be so planned and conducted as to interfere in the least possible manner with the business of the said railroad. In case the railroad...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-47.htm - 2K - Match Info - Similar pages
|