9-9-31
Section 9-9-31 Tax levy to defray expenses of proposed works and improvements generally; water management tax record; additional taxes. (a) After the list of lands and other property with the assessed benefits and the decree and judgment of the court have been filed as provided in Section 9-9-29, the board of water management commissioners shall without unnecessary delay levy a tax of such portion of said benefit on all lands and other property in the district to which benefits have been assessed as may be found necessary by the board of water management commissioners to defray the costs and expenses of the proposed works and improvements as incorporated in the plan of water management, plus 10 percent of said total amount for emergencies. The said tax shall be apportioned to and levied on each tract of land or other property in said district in proportion to the benefits assessed and not in excess of 90 percent thereof; and, in case bonds are issued as provided in this article, then...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-31.htm - 5K - Match Info - Similar pages
11-48-4
Section 11-48-4 General powers of municipalities as to public improvements. All cities or towns in this state may design or cause to be designed, contract for and execute or cause to be executed a contract for the construction of the following named improvements or reimprovements to the streets or any portions thereof and the following named sewers or sewer systems and the following named water and gas mains and service connections. All cities or towns in this state having a population of 60,000 inhabitants or more according to the most recent federal census may design or cause to be designed, contract for and execute or cause to be executed a contract for the construction of the following named drainage improvements or drainage systems or reclamation systems and the filling in of swamps or inundated or overflowed or submerged lands within the limits of such municipality. All cities or towns in this state may design or cause to be designed, contract for and execute or cause to be...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/11-48-4.htm - 7K - Match Info - Similar pages
9-9-48
Section 9-9-48 Control and supervision of completed improvements; annual tax for repairs and maintenance; payment of costs of repairs and maintenance; injury, damage or obstruction of improvements. Whenever any improvement constructed under this article is completed, it shall be under the control and supervision of the board of water management commissioners. It shall be the duty of said board to maintain the levees, ditches, drains, watercourses, floodwater retarding structures and any other improvements in good repair, and for this purpose the board of water management commissioners may annually levy a tax on the lands benefited by the construction of such improvement in the same manner as other water management taxes are levied, not to exceed 10 percent of the assessed benefits in any one year, and the fund that is collected shall be used for repairing and maintaining the ditches, drains, watercourses, floodwater retarding structures and other improvements in perfect order;...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-48.htm - 2K - Match Info - Similar pages
9-9-29
Section 9-9-29 Filing of exceptions to report; hearing upon exceptions and report; approval and confirmation of report; dismissal of proceedings and dissolution of district; transmittance of copies of court decree and report of viewers; filing fee. On or before the day set for the hearing of the final report of the board of viewers, the water management district or any owner of land or other property in said district or any person having an interest in any lands or other property within said district may file exceptions to said report or to any assessment for either benefits or damages. All exceptions shall be heard by the court and determined in a summary manner so as to carry out liberally the purposes and needs of the district. If it appears to the satisfaction of the court, after having heard and determined all of said exceptions, that the estimated cost of constructing the improvements contemplated in the plan of water management or, in the case of a Public Law 566 watershed...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-29.htm - 3K - Match Info - Similar pages
9-9-27
Section 9-9-27 Viewing and assessment of lands by board of viewers; report of findings. (a) Within 30 days after qualifying, the board of viewers shall begin its duties, and it may at any time call upon the attorney of the district for legal advice and information relative to its duties. Said viewers shall proceed to view the premises and determine the value of all land and other property within or without the district to be acquired and used for rights-of-way or other works of drainage, leveeing, reclamation, flood prevention or for the conservation, development, utilization and disposal of water as set out in the water management plan. They shall assess the amount of benefits and the amount of damages, if any, that will accrue to each tract of 40 acres or less, according to the legal or recognized subdivisions of land according to ownership, to public highways, railroad and other rights-of-way, railroads, roadways and other property from carrying out and putting into effect the plan...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/9-9-27.htm - 3K - Match Info - Similar pages
18-1A-171
Section 18-1A-171 Reduction of compensation award because of incidental benefits from taking. The amount of compensation to which the owners and other parties interested therein are entitled must not be reduced or diminished because of any incidental benefits which may accrue to them or to their remaining lands in consequence of the uses to which the lands to be taken or in which the easement is to be acquired will be appropriated; provided, that in the condemnation of lands for ways and rights-of-way for public highways, water or sewer lines, the commissioners or jury may, in fixing the amount of compensation to be awarded the owner for lands taken for this use, take into consideration the value of the enhancement to the remaining lands of such owner that such highway, water or sewer lines may cause; and provided further, that in proceedings instituted by water conservancy districts and water management districts, benefits accruing to the landowner from an improvement may be...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/18-1A-171.htm - 3K - Match Info - Similar pages
11-99A-6
Section 11-99A-6 Powers of a district. Any district shall have the following powers, in addition to those stated elsewhere in this chapter: (1) To have perpetual existence, subject to termination as herein provided. (2) To have and use a corporate seal, but the use of a corporate seal on any document shall not be required for the validity of a document or the due execution and delivery thereof. (3) To sue and to be sued and to be a party to suits, actions, and proceedings, but subject to the limitations on liability and the immunity granted in this chapter. (4) To enter into contracts and agreements affecting the affairs of the district, including contracts with the United States of America and any other public person. (5) To borrow money and to incur indebtedness and to evidence the same by bonds, all without an election. (6) To acquire and dispose of land, real property, personal property, and interests therein of any nature. (7) To acquire, construct, install, and operate...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/11-99A-6.htm - 5K - Match Info - Similar pages
35-11-210
Section 35-11-210 Lien declared. Every mechanic, person, firm, or corporation who shall do or perform any work, or labor upon, or furnish any material, fixture, engine, boiler, waste disposal services and equipment, or machinery for any building or improvement on land, or for repairing, altering, or beautifying the same, under or by virtue of any contract with the owner or proprietor thereof, or his or her agent, architect, trustee, contractor, or subcontractor, upon complying with the provisions of this division, shall have a lien therefor on such building or improvements and on the land on which the same is situated, to the extent in ownership of all the right, title, and interest therein of the owner or proprietor, and to the extent in area of the entire lot or parcel of land in a city or town; or, if not in a city or town, of one acre in addition to the land upon which the building or improvement is situated; or, if employees of the contractor or persons furnishing material to him...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/35-11-210.htm - 3K - Match Info - Similar pages
11-89C-4
Section 11-89C-4 Powers of public corporation; requirements for development or adoption of rules, procedures, ordinances, etc. (a) When expressly required to comply with storm water laws, any public corporation created pursuant to this chapter shall have the following powers: (1) To establish, maintain, and operate an organizational structure pursuant to this chapter, its original or amended certification, and its bylaws or other rules of procedure, that will enable it to implement the storm water laws for and on behalf of any governing body that exercises the option to participate in or with a public corporation, provided that no new or greater authorities or powers other than those specifically granted to the governing bodies are conferred upon any public corporation formed pursuant to this chapter. Except for the authority provided in subdivision (20), authority to enforce the storm water laws is retained wholly and exclusively to the governing bodies and may not be further...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/11-89C-4.htm - 10K - Match Info - Similar pages
33-2-180
Section 33-2-180 Definitions. Where used in this article the following words and terms shall be given the following respective meanings unless the context hereof clearly indicates otherwise: (1) CODE. The Code of Alabama 1975, as amended. (2) DEPARTMENT. Alabama State Docks Department created in Chapter 1 of Title 33. (3) DIRECTOR. The Director of State Docks provided for in Section 33-1-3. (4) DOCKS FACILITIES. Docks and all kinds of docks facilities, including elevators, compresses, conveyors, warehouses, water and rail terminals, bulk handling facilities, coal handling facilities, grain elevator facilities, wharves, piles, quays, cold storage facilities, loading and unloading facilities, and other related structures, facilities, equipment, property and improvements of every kind needful for the convenient use of same, in aid of commerce and use of the waterways of the state, now or hereafter existing, that are now or hereafter owned or held, are or are to be under the management and...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/33-2-180.htm - 4K - Match Info - Similar pages
|