45-31-130.09
Section 45-31-130.09 Inspection and approval of materials The county engineer shall make written
requisition to the county purchasing agent for all materials, machinery, equipment, and necessary
supplies needed for the construction, maintenance, or repair of the public roads, bridges,
and ferries of the county. Such requisitions shall be filed and presented by the chair to
the commission at its next meeting, for the approval of the commission. Provided, however,
that the county purchasing agent shall have full power and authority to make the purchases
without first obtaining the approval of the commission if the delay might, in his or her judgment,
cause an unnecessary and harmful interruption in the operation of the county road system,
providing the purchases are made in accordance with prevailing law. The county purchasing
agent shall be solely responsible and accountable for purchasing the materials, machinery,
equipment, and supplies under the approved requisitions, and shall...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-31-130.09.htm - 1K - Match Info - Similar pages

45-44-130.08
Section 45-44-130.08 Requisition for materials, supplies, etc.; authority and accountability
of county purchasing agent. The county engineer shall make written requisition to a county
purchasing agent for all materials, machinery, equipment, and necessary supplies needed for
the construction, maintenance, or repair of the public roads, bridges, and ferries of Macon
County. The requisitions shall be filed and presented by the chair to the commission at its
next meeting, for the approval of the commission. The county purchasing agent may make purchases
without first obtaining the approval of the county commission if in the judgement of the engineer,
the delay caused by this procedure may cause an unnecessary and harmful interruption in the
operation of the county road system. The purchases shall be made in accordance with prevailing
law. The county purchasing agent shall be solely responsible and accountable for purchasing
the materials, machinery, equipment, and supplies under the...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-44-130.08.htm - 1K - Match Info - Similar pages

45-7-130.09
Section 45-7-130.09 Requisition for materials, supplies, etc., authority and accountability
of County Purchasing Agent. The county engineer shall make written requisition to the county
purchasing agent for all materials, machinery, equipment, and necessary supplies needed for
the construction, maintenance, or repair of the public roads, bridges, and ferries of Butler
County. The requisitions shall be filed and presented by the chair to the commission at its
next meeting, for the approval of the commission. The county purchasing agent may make purchases
without first obtaining the approval of the Butler County Commission if in the judgment of
the engineer, the delay caused by this procedure may cause an unnecessary and harmful interruption
in the operation of the county road system. The purchases shall be made in accordance with
prevailing law. The county purchasing agent shall be solely responsible and accountable for
purchasing the materials, machinery, equipment, and supplies under...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-7-130.09.htm - 1K - Match Info - Similar pages

45-16-130.09
Section 45-16-130.09 Requisition for materials, supplies, etc.; authority and accountability
of county purchasing agent. The county engineer shall make written requisition to the county
purchasing agent for all materials, machinery, equipment, and necessary supplies needed for
the construction, maintenance, or repair of the public roads, bridges, and ferries of Coffee
County. Such requisitions shall be filed and presented by the chairman to the commission at
its next meeting, for the approval of the commission. Provided, however, that the county purchasing
agent shall have full power and authority to make purchases without first obtaining the approval
of the Coffee County Commission if the delay caused by the hereinabove procedure, might, in
his or her judgment, cause an unnecessary and harmful interruption in the operation of the
county road system, providing the purchases are made in accordance with prevailing law. The
county purchasing agent shall be solely responsible and...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-16-130.09.htm - 1K - Match Info - Similar pages

45-26-130
Section 45-26-130 Appointment and employment; duties; compensation; equipment and facilities.
(a) This section shall apply only in Elmore County. (b) The Elmore County Commission shall
appoint and employ a county engineer or chief engineer, who shall be a thoroughly qualified
and competent professional engineer. The county engineer or chief engineer shall possess all
of the qualifications as specified for county engineers or chief engineers under the general
laws of the State of Alabama. The county engineer or chief engineer shall be responsible for
the maintenance and construction of the public roads, bridges, and ferries in the county and
shall perform other duties related to his or her appointment as may be assigned by the county
commission. The county engineer or chief engineer shall serve at the pleasure of the county
commission. (c) It shall be the duty of the county engineer or chief engineer to carry out
the following as determined by the county commission: (1) Employ,...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-26-130.htm - 6K - Match Info - Similar pages

45-11-244.10
Section 45-11-244.10 Use of proceeds. The proceeds of any taxes levied pursuant to the authorization
contained in this part shall be used only for the purpose of providing funds to pay the costs
of construction, maintenance, and operation of hospital facilities in the county. The entire
proceeds derived by the county from the taxes herein authorized to be levied, including any
income derived from the investment of such proceeds, shall be paid over and deposited, promptly
upon receipt thereof, into a separate and distinct fund or account of the county, which shall
be accounted for as other county funds; provided, however, the governing body of the county
shall have the further power to designate as the agency of the county to construct, maintain,
and operate the hospital facilities any public hospital corporation heretofore or hereafter
organized for hospital purposes in the county. When a public hospital corporation shall be
so designated, the proceeds of the taxes thereafter collected...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-11-244.10.htm - 2K - Match Info - Similar pages

45-11-245.09
Section 45-11-245.09 Use of proceeds. The proceeds of any taxes levied pursuant to the authorization
contained in this part shall be used only for the purpose of providing funds to pay the costs
of construction, maintenance, and operation of hospital facilities in the county. The entire
proceeds derived by the county from the taxes herein authorized to be levied, including any
income derived from the investment of such proceeds, shall be paid over and deposited, promptly
upon receipt thereof, into a separate and distinct fund or account of the county, which shall
be accounted for as other county funds; provided, however, the governing body of the county
shall have the further power to designate as the agency of the county to construct, maintain,
and operate the hospital facilities any public hospital corporation heretofore or hereafter
organized for hospital purposes in the county. When a public hospital corporation shall be
so designated, the proceeds of the taxes thereafter collected...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-11-245.09.htm - 2K - Match Info - Similar pages

45-29-71.10
Section 45-29-71.10 County supervisor. (a) The county commission may, by designating one of
its employees or, in its discretion, employ as new personnel, a county supervisor. The county
supervisor shall serve at the pleasure of the county commission and his or her compensation
shall be fixed by the county commission. It shall be the duty of the county supervisor of
Fayette County to do all of the following: (1) To supervise and direct all personnel as are
necessary to properly maintain and construct the public roads, highways, bridges, and county
shop of Fayette County, and he or she shall have authority to prescribe their duties subject
to the policies which are in effect or established by the county commission. (2) To maintain
the necessary accounting funds and records to reflect the cost of the county highway system.
(3) To build or construct new roads, or change old roads. (4) To make recommendations for
a yearly work plan and present budget information for the new year. (5) To...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-29-71.10.htm - 4K - Match Info - Similar pages

45-44-72.04
Section 45-44-72.04 Powers and duties of commissioners. Each member of the county commission
may inspect the roads and bridges of his or her district from time to time. The members of
the county commission may also assist in securing right-of-way and assist in public relations
generally. Each member of the county commission may elect to direct a crew to maintain the
unpaved roads in his or her district and to address the complaints and concerns of the citizens
of his or her district. The personnel and equipment for any such crew shall be determined
by the county commission in session, and the expenses for any crew shall come out of the overall
budget for the construction, maintenance, and repairs of the county roads, bridges, and ferries
of Macon County. Any commissioner electing to direct a crew shall be the custodian and accountable
to the county commission for all road machinery, equipment, tools, supplies, and repair parts
owned by Macon County and used by his or her crew. The...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/45-44-72.04.htm - 1K - Match Info - Similar pages

34-8-7
Section 34-8-7 Exemptions from chapter; subcontractor requirements. (a) The following shall
be exempted from this chapter: (1) The practice of general contracting, as defined in Section
34-8-1, by an authorized representative or representatives of the United States Government,
State of Alabama, incorporated town, city, or county in this state, which is under the supervision
of a licensed architect or engineer provided any work contracted out by the representative
shall comply with the provisions of this chapter for general contractor. (2) The construction
of any residence or private dwelling. (3) A person, firm, or corporation constructing a building
or other improvements on his, her, or its own property provided that any of the work contracted
out complies with the definition in this chapter for general contractor. A municipal governing
body or municipal regulatory body may not enact any ordinance or law restricting or altering
this exemption. Any municipal ordinance or regulation...
alisondb.legislature.state.al.us/alison/CodeOfAlabama/1975/34-8-7.htm - 5K - Match Info - Similar pages